Change Order Accounting and Notification of Changes; FAR Sections Affected: 52.243-4, 52.243-6, 52.243-7

ICR 202206-9000-004

OMB: 9000-0026

Federal Form Document

Forms and Documents
Document
Name
Status
Supporting Statement A
2022-06-28
IC Document Collections
IC ID
Document
Title
Status
36425
Modified
254426
New
254425
New
ICR Details
9000-0026 202206-9000-004
Received in OIRA 201909-9000-004
FAR
Change Order Accounting and Notification of Changes; FAR Sections Affected: 52.243-4, 52.243-6, 52.243-7
Extension without change of a currently approved collection   No
Regular 06/28/2022
  Requested Previously Approved
36 Months From Approved 10/31/2022
9,240 17,215
9,240 17,215
545,160 946,825

Contractors must submit to comply with the Federal Acquisition Regulation (FAR) part 43 requirements as stated in the following clauses: a. 52.243-4, Changes. For acquisitions for dismantling, demolition, or removal of improvements; and fixed-price construction contracts that exceed the simplified acquisition threshold (SAT), the contractor must assert its right to an adjustment under this clause within 30 days after receipt of a written change order or the furnishing of a written notice, by submitting to the contracting officer a written statement describing the general nature and amount of proposal, unless this period is extended by the Government. The written notice covers any other written or oral order (which includes direction, instruction, interpretation, or determination) from the contracting officer that causes a change. The contractor gives the contracting officer written notice stating (1) the date, circumstances, and source of the order and (2) that the contractor regards the order as a change order. The statement of proposal for adjustment may be included in the written notice. b. 52.243-6, Change Order Accounting. The contracting officer may require change order accounting whenever the estimated cost of a change or series of related changes exceeds $100,000. The contractor, for each change or series of related changes, shall maintain separate accounts, by job order or other suitable accounting procedure, of all incurred segregable, direct costs (less allocable credits) of work, both changed and not changed, allocable to the change. The contractor shall maintain these accounts until the parties agree to an equitable adjustment or the matter is conclusively disposed of under the Disputes clause. This requirement is necessary in order to be able to account properly for costs associated with changes in supply and research and development (R&D) contracts of significant technical complexity, if numerous changes are anticipated, or construction contracts if deemed appropriate by the contracting officer. c. 52.243-7, Notification of Changes. The clause is available for use primarily in negotiated R&D or supply contracts for the acquisition of major weapon systems or principal subsystems. If the contract amount is expected to be less than $1,000,000, the clause shall not be used, unless the contracting officer anticipates that situations will arise that may result in a contractor alleging that the Government has effected changes other than those identified as such in writing and signed by the contracting officer. The contractor shall notify the Administrative Contracting Officer in writing if the contractor identifies any Government conduct (including actions, inactions, and written or oral communications) that the contractor regards as a change to the contract terms and conditions. This excludes changes identified as such in writing and signed by the contracting officer. On the basis of the most accurate information available to the contractor, the notice shall state— (1) The date, nature, and circumstances of the conduct regarded as a change; (2) The name, function, and activity of each Government individual and Contractor official or employee involved in or knowledgeable about such conduct; (3) The identification of any documents and the substance of any oral communication involved in such conduct; (4) In the instance of alleged acceleration of scheduled performance or delivery, the basis upon which it arose; (5) The particular elements of contract performance for which the Contractor may seek an equitable adjustment under this clause; (6) The Contractor's estimate of the time by which the Government must respond to the Contractor's notice to minimize cost, delay or disruption of performance.

None
None

Not associated with rulemaking

  87 FR 24163 04/22/2022
87 FR 38406 06/28/2022
No

3
IC Title Form No. Form Name
Change Order Accounting
Changes
Notification of Changes

  Total Request Previously Approved Change Due to New Statute Change Due to Agency Discretion Change Due to Adjustment in Estimate Change Due to Potential Violation of the PRA
Annual Number of Responses 9,240 17,215 0 -7,975 0 0
Annual Time Burden (Hours) 9,240 17,215 0 -7,975 0 0
Annual Cost Burden (Dollars) 545,160 946,825 0 -401,665 0 0
Yes
Miscellaneous Actions
Yes
Miscellaneous Actions
This extension includes updates to the burden as follows: • Current Data and Information. The estimated number of respondents and responses per year is based on FPDS data for the five most recent fiscal years (2017 through 2021). The parameters for data pulled from FPDS for each clause is consistent with the prescription, which may have resulted in changes to the number of respondents and average contracts per respondent for the individual burden estimates. • FAR 52.243-6, Change Order Accounting. This extension recognizes that the burden under this clause is only for recordkeeping. There is no reporting burden associated with this clause. • The estimated cost to the public and to the Government was updated based on use of calendar year 2022 OPM GS wage rates for the rest of the United States.

$67,968
No
    No
    No
No
No
No
No
Edward Loeb 2025010650 Edward.Loeb@gsa.gov

  No

On behalf of this Federal agency, I certify that the collection of information encompassed by this request complies with 5 CFR 1320.9 and the related provisions of 5 CFR 1320.8(b)(3).
The following is a summary of the topics, regarding the proposed collection of information, that the certification covers:
 
 
 
 
 
 
 
    (i) Why the information is being collected;
    (ii) Use of information;
    (iii) Burden estimate;
    (iv) Nature of response (voluntary, required for a benefit, or mandatory);
    (v) Nature and extent of confidentiality; and
    (vi) Need to display currently valid OMB control number;
 
 
 
If you are unable to certify compliance with any of these provisions, identify the item by leaving the box unchecked and explain the reason in the Supporting Statement.
06/28/2022


© 2024 OMB.report | Privacy Policy